Effective Date: 12/23/2024
Welcome to On Point Building & Remodeling LLC (“we,” “our,” “us”). These Terms and Conditions govern your use of our services, website, and any associated content or communications.
1. Acceptance of Terms
By engaging our services or accessing our website, you agree to be bound by these Terms and Conditions. If you do not agree, please refrain from using our services or website.
2. Scope of Services
On Point Building & Remodeling LLC provides home building and remodeling services, including but not limited to custom construction, kitchen renovations, bathroom upgrades, and other related services (“Services”). The specific scope of work will be outlined in a written agreement or contract for each project.
3. Quotes and Pricing
- All quotes provided are estimates based on the information available at the time.
- Final pricing may vary due to changes in scope, unforeseen conditions, or customer-requested modifications.
- Any changes to the project scope must be documented and agreed upon in writing by both parties.
4. Payment Terms
- Payment schedules will be outlined in the project agreement.
- Late payments may incur additional fees or interest as specified in the agreement.
- Failure to make payments may result in project delays or termination.
5. Project Timeline
- Project timelines are estimates and may be affected by weather, availability of materials, or other unforeseen circumstances.
- We will communicate any significant delays and work collaboratively to adjust schedules as necessary.
6. Customer Responsibilities
Customers agree to:
- Provide timely access to the property for project work.
- Communicate clearly regarding preferences, changes, or concerns.
- Ensure the worksite is free of personal items or obstructions that could delay progress.
7. Warranties and Liability
- We stand by the quality of our work and will address defects or issues within the warranty period specified in the project agreement.
- On Point Building & Remodeling LLC is not responsible for:
- Pre-existing structural issues or code violations.
- Damage caused by third-party contractors or customer misuse.
- Unforeseen issues such as hidden mold, asbestos, or other hazardous materials.
8. Intellectual Property
All content on our website, including text, images, and designs, is the property of On Point Building & Remodeling LLC and is protected by copyright laws. Unauthorized use is prohibited.
9. Termination
We reserve the right to terminate services if:
- Payment terms are not met.
- The customer fails to comply with these Terms and Conditions.
- Mutual agreement to discontinue the project is reached.
10. Dispute Resolution
- Any disputes arising from our services will be resolved through mediation or arbitration, as mutually agreed upon.
- Legal proceedings, if necessary, shall be conducted in [State/City].
11. Governing Law
These Terms and Conditions are governed by the laws of the State of [Insert State], without regard to its conflict of law principles.
12. Changes to Terms
We may update these Terms and Conditions at any time. Changes will be effective upon posting to our website. Customers will be notified of significant updates.
13. Contact Information
For questions about these Terms and Conditions or our services, contact us at:
On Point Building & Remodeling LLC
Phone: 860-908-4272
Email: CLICK HERE
Address: 3 Stone House Drive Moosup, Ct 06354